Terms & Conditions
Should there be time when the field engineers spend time on-site performing duties other than described in scope matrix (ARBC Scope) or where
the ARBC scope duties cannot be performed due to deficiency in plant equipment, plant operation or other reasons not attributed directly to
ARBC, ARBCwill not be held Responsible. For any delay in project schedule, however ARBC will have the right to charge over time for this period of
extension or delay in the project schedule.
Validity: This offer is valid for a period of 30 days from the offer date. Please ask for explicit validity extension beyond that.
Price Basis: Ex-Works Noida.
Freight: Extra as actual.
Taxes : Taxes: The Prices quoted are basic Prices, exclusive of all taxes & duties, which shall be extra as applicable at time of supply. The rates of taxes &duties are controlled by the government & ARBC Company shall levy the same. Present rate of GST is 18%.
Payment Terms
50% advance and balance 50 %against Proforma Invoice along with all taxes & charges before dispatch of the material.
Delivery
Readiness at works within 5/6 weeks after receipt of your technically commercially clear order along with advance
Warranty
Stand for 1 years against any manufacturing defects from the date of invoice/delivery.
Change Order:
Any change in order shall be by prior written mutual consent only.
Rules:
The ARBC engineer shall abide by all customer safety & other rules applicable to contract workers & brought to notice of ARBC prior to release of PO. We shall also abide by any other rules also brought to our notice, provided it does not have any commercial implication to ARBC.
Non – Solicitation Agreement:
During the currency of the contract & three years after the expiry of contract; customer shall not solicit the ARBC employees for employment directly or indirectly, except with written consent of ARBC.
Confidentiality Clause:
During the currency of the contract & three years after the expiry of contract; each party will maintain in strict confidence all technical and business data and information disclosed by one party to the other. Neither party will disclose the existence of this contract Agreement or its terms to thirdparty without consent of the other party.
Limitation of Liability:
In no event, ARBC shall be liable for any consequential loss or damages arising out of or connected with this PO in any way whatsoever.
Force Majeure:
Seller will not be liable for failure to perform any obligation or delay in performance resulting from any cause beyond the reasonable control ofSeller or its suppliers or from any act of God; act of civil or military authority; act or war whether declared or undeclared; act (including delay, failureto act, or priority) of any governmental authority, purchaser, purchaser’s customer or other contractors; or civil disturbance; insurrection or riot;sabotage; fire; inclement weather conditions; earthquake; flood; strike; work stoppage or other labour difficulty; embargo; fuel or energy shortage;wreck; major equipment or product breakdown; delay or accident in shipping or transportation; or failure or delay beyond its reasonable control inobtaining necessary manufacturing facilities, labor or materials from its usual sources. In the event of delay in Performance excusable under thisArticle, the time for performance of the work will be extended by a period of time reasonably necessary to overcome the effect of the delay.
Cancellation:
Under no circumstances, the PO is liable for one-side cancellation. If the purchaser cancels the PO, the Advance shall be forfeited. Allthe payments shall become payable immediately.
Arbitration:
Any difference of opinion arising between the parties out of or in connection with the contract or its implementation shall be settled amicably.Should this, contrary to expectations, not be possible, then the matter shall be subject to Jurisdiction of the court of Noida India.
Outstanding Payment and Pending GST credits / statutory requirements:
Irrespective of confirmed /agreed support delivery schedule, ARBC Systems LLP is not liable for adhering toa timely delivery schedule owing to pending overdue payment and GST credits / statutory requirements.
Ordering Information/ Details
Absolutely Right Balance & Committed Company
Works: East Babarpur Near Chauhan Optical’s, New Delhi-32
PAN: BNQPC5001D
GSTIN: 07BNQPC5001D1Z